Tully Civic Centre External Building Remediation, Repainting and Signage Works

Cassowary Coast Regional Council is seeking quotations from suitably qualified contractors for the 104657 – Tully Civic Centre External Building Remediation, Repainting and Signage Works located at 34-40 Bryant Street, Tully QLD 4854.

The Works generally include external building remediation and repainting works, scaffolding and access requirements, removal and installation of signage, cleaning and preparation of external surfaces, dilapidation surveys, and associated ancillary works in accordance with the Request for Quotation documents.

Respondents are required to submit a proposed program for the Works. The Works must be completed by 31 May 2027.

Refer to the RFQ documents for the full scope, specifications, drawings, pricing schedule and response requirements.

Background information / Compatibility requirements

Refer to the RFQ documents for the full scope of works, specifications, drawings and response requirements. Respondents are responsible for verifying site conditions, quantities and access requirements prior to submitting a quotation.

Desired Outcomes ('Nice to haves', Conditions & Warranties, SLA's, Project benefits): Delivery of a high-quality external building remediation, repainting and signage project in accordance with the Contract Documents.

Restoration and protection of the external building envelope to improve asset condition and extend the service life of the facility.

Compliance with the nominated paint systems, specifications, manufacturer's requirements and warranty conditions.

Minimal disruption to Council operations, staff, facility users and the general public during the Works.

Safe management of pedestrian access and work areas throughout the project.

Timely completion of the Works by 31 May 2027.

Identification and reporting of any defects, substrate deterioration, water ingress issues, cladding defects or other conditions requiring rectification.

Delivery of all required warranties, photographic records, dilapidation surveys and handover documentation at Practical Completion.

Preference may be given to respondents who demonstrate practical experience in similar remediation and repainting projects, strong project programming, effective risk management, and the ability to minimise disruption while completing the Works safely and efficiently.

Questions asked by the buyer:

The Respondent shall nominate the total duration required to complete the Works from commencement on Site to Practical Completion.

Proposed Duration (calendar weeks): ______ weeks

Proposed Earliest Commencement Date: ______

Proposed Practical Completion Date: ______

Scaffold and Access Strategy Is Scaffolding required to complete the works? Yes No

Alternative Paint Systems If proposing a paint system other than the specified Dulux paint system, does the proposed system provide an equivalent or greater manufacturer warranty period and coverage? ? Yes ? No

If the Respondent proposes a paint system other than that specified, the Respondent shall confirm whether the proposed system provides an equivalent or greater manufacturer's warranty, product performance, durability and service life. Details of the proposed warranty period, coverage, exclusions and supporting documentation shall be provided with the Response.

Buyer: Cassowary Coast Regional Council

Buyer location: Butler St, Tully, Queensland 4854, Australia

VendorPanel reference: VP521859

Buyer's reference: 104657

Opens: Thursday 10 September 2026 (E. Australia Standard Time)

Closes: Thursday 01 October 2026 05:00 PM (E. Australia Standard Time)

Supplier query cut-off: Thursday 01 October 2026 05:00 PM (E. Australia Standard Time)

Expected decision: Thursday 15 October 2026 (E. Australia Standard Time)

Categories: Building Products & Materials; 1: Paint; Building Trade & Repairs & Maintenance Services; 1: Building Maintenance & Services; 2: Painting Supplies & Services; 3: Roofing Services

Regions of service: Queensland; 1: Far North; 2: Northern; All Regions of Service locations are within Australia.

Tender documents: 9

Published on VendorPanel Public Tenders. Documents and responses require free VendorPanel supplier registration.