SPE60526Q0269 - FT. Stewart, GA 8, 500 USG Gasoline, Automotive (MUR) Required Delivery Date (RDD) 17 September

DEPT OF DEFENSE · DEFENSE LOGISTICS AGENCY · DLA ENERGY · DLA ENERGY is soliciting SPE60526Q0269 - FT. Stewart, GA 8, 500 USG Gasoline, Automotive (MUR) Required Delivery Date (RDD) 17 September 2026. Solicitation number SPE60526Q0269. Classified under NAICS 324110 — Petroleum Refineries. Product/service code 9130 — LIQUID PROPELLANTS AND FUELS, PETROLEUM BASE. Place of performance: GA, USA. Responses are due by 17 September 2026 16:00 UTC. Posted on SAM.gov, the US federal contract opportunities system; registration is required to bid.

This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.2 of the Revolutionary FAR Overhaul (RFO), as supplemented with additional information included in this notice. Quotes are being requested and a written solicitation will not be issued. The purchase order resulting from this procurement will be a firm fixed-price Purchase Order. This opportunity is restricted to 100% Set Aside for Small Business Award. NAICS code 324110 size standard is 1,500 employees. The solicitation, SPE605-26-Q-0269, is issued as a Request for Quotation (RFQ), under RFO part 12 (Acquisition of Commercial Products and Commercial Services). This document and incorporated provisions and clauses are those in effect through the Revolutionary Federal Acquisition Regulation Overhaul (RFO) Effective Date 02/01/2026, and Defense Federal Acquisition Regulation Supplement (DFARS): DFARS Change 05/07/2026, effective date 05/07/2026; DPAS rating for potential award is PO. The clauses and provisions referenced in this solicitation may be reviewed/obtained in full text form at https://www.acquisition.gov. The prompt payment act is applicable.

NOTE: All offers shall be registered in System of Award Management (SAM), Small Business Administration (SBA), under NACIS 324110.

Scope of Contract:

CLIN 0001 – The contractor shall provide under line item 0001:

Fuel Type: Gasoline, Automotive (MUR)

NSN: 9130-00-148-7103

Delivery Address: Bldg 1860 SF 40 Tank Trail Fort Stewart GA 31314

Quantity: 8,500 USG

Required Delivery Date: 17 September 2026

Delivery Hours: Between 7:30 AM and not later than 2:30 PM (Fort Belvoir, VA Time)

Delivery Mode: Tank Truck w/ Pump

Delivery Note: "VAPOR RECOVERY REQUIRES 4 1/2" FEMALE ADAPTER 4"HOSE TO UNLOAD FUEL

No. of Tanks        Capacity         Type               Tank Location 1             20000            ABOVE GROUND TANK(S)      BLDG 1860

Special Note:

1. Inspection and Acceptance at Destination

2. Ensure driver carries two forms of I.D

FOB Destination. Electronic Funds Transfer as a means of payment will be made upon receipt and acceptance of all products through Wide Area WorkFlow (WAWF). The following provisions and clauses apply to this acquisition: FAR 52-212- 1, Instructions to Offerors Commercial Products and Commercial Services; FAR 52.212-2 Evaluation of Commercial Products and Commercial Services; the evaluation criteria stated in paragraph (a) of the provision are as follows: Lowest Price Technically Acceptable. The contract award will be offered to the best value offer made to the Government, considering price, technical capability, and past performance. FAR 52.212-4, Terms and Conditions—Commercial Products and Commercial Services. FAR 52.246-2, and the following apply: FAR 52.211-11, DFARS 252.203-7000, 252.225-7021, and 252.232-7003 shall be applicable.

*Note: The government will not assume any responsibility above the 10% variance authorized by the contract.*

Variation in Quantity (a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b). (b) The permissible variation shall be limited to: _10__ Percent increase _10__ Percent decrease This increase or decrease shall apply to ____________.* * Contracting Officer shall insert in the blank the designation(s) to which the percentages apply, such as- (1) The total contract quantity; (2) Item1 only; (3) Each quantity specified in the delivery schedule; (4) The total item quantity for each destination; or (5) The total quantity of each item without regard to destination. PLEASE NOTE: DoD installations and Federal Government facilities have access control measures and procedures in place. You and your subcontractor are responsible for knowing and complying with all physical security measures and access control procedures on the DoD installation or Federal Government facility you are delivering to. Be aware that gaining access to a DoD installation or Federal Government facility can be a lengthy process. DLA Energy is not responsible for any delays at physical security check points and will not pay for any costs incurred as a result of delays at physical security check points. Quotes containing accelerated payment terms or additional fees/costs for delays caused at government physical security check points will not be considered. Responsible offerors shall submit quotes to Jermaine Smith, Contract Specialist, at email [contact details removed] and [contact details removed] are due by Wednesday, September 16, 2026, 12:00 P.M., Fort Belvoir, VA, time. Offerors shall include all applicable taxes and fees in the offer price. DLA Energy appreciates your interest in this requirement.