FreeTender
Accepting bidstenderBrazil

Contratação de empresa especializada para a prestação de serviços de engenharia destinados à execução da obra de construção de novas salas de aula e ampliação da escola de ensino fundamental do município de aparecida do RIO doce – GO, correspondente à 2ª etapa da obra, conforme as especificações, condições e…

Issued by MUNICIPIO DE APARECIDA DO RIO DOCE · FMDE · via PNCP — Brazil national public procurement portal

Published
25 Sept 2026
Closes
22 Oct 2026, 10:00 UTC
Reference
24859316000100-1-000252/2026
Location
Aparecida do Rio Doce, GO, Brazil
Sector
Construction & Infrastructure

Details

MUNICIPIO DE APARECIDA DO RIO DOCE · FMDE is tendering: Contratação de empresa especializada para a prestação de serviços de engenharia destinados à execução da obra de construção de novas salas de aula e ampliação da escola de ensino fundamental do município de aparecida do RIO doce – GO, correspondente à 2ª etapa da obra, conforme as especificações… PNCP reference 24859316000100-1-000252/2026. Procurement modality: Concorrência - Eletrônica. Estimated value R$ 648,335.99. Place of performance: Aparecida do Rio Doce, GO, Brazil. Legal basis: Lei 14.133/2021, Art. 28, II . Proposals close on 22 October 2026 10:00 UTC. Published on PNCP, Brazil's national public procurement portal. Notice text is in Portuguese.

Objeto: CONTRATAÇÃO DE EMPRESA ESPECIALIZADA PARA A PRESTAÇÃO DE SERVIÇOS DE ENGENHARIA DESTINADOS À EXECUÇÃO DA OBRA DE CONSTRUÇÃO DE NOVAS SALAS DE AULA E AMPLIAÇÃO DA ESCOLA DE ENSINO FUNDAMENTAL DO MUNICÍPIO DE APARECIDA DO RIO DOCE – GO, CORRESPONDENTE À 2ª ETAPA DA OBRA, CONFORME AS ESPECIFICAÇÕES, CONDIÇÕES E EXIGÊNCIAS ESTABELECIDAS NOS PROJETOS BÁSICOS, PROJETOS EXECUTIVOS, MEMORIAL DESCRITIVO, PLANILHA ORÇAMENTÁRIA, CRONOGRAMA FÍSICO-FINANCEIRO, COMPOSIÇÕES DE CUSTOS E DEMAIS DOCUMENTOS TÉCNICOS INTEGRANTES DO PROCESSO LICITATÓRIO.

Informação complementar: Contratação de empresa especializada para a prestação de serviços de engenharia destinados à execução da obra de construção de novas salas de aula e ampliação da Escola de Ensino Fundamental do Município de Aparecida do Rio Doce – GO, correspondente à 2ª Etapa da obra, conforme as especificações, condições e exigências estabelecidas nos Projetos Básicos, Projetos Executivos, Memorial Descritivo, Planilha Orçamentária, Cronograma Físico-Financeiro, Composições de Custos e demais documentos técnicos integrantes do processo licitatório.

Context for bidders

There are 1,891 open Construction & Infrastructure tenders in Brazil. This one closes in 27 days.

Similar Construction & Infrastructure tenders

Before you bid on this tender

A quick checklist to help you decide whether to bid and prepare a compliant submission for this construction & infrastructure opportunity. Always verify the details on the official source.

  • Confirm the exact closing date and time (and time zone) on the official portal — deadlines are strict and can be revised by a corrigendum.
  • Read the full notice and every attached document, including the scope, specifications and any bill of quantities or terms of reference.
  • Check the eligibility criteria — prior similar experience, annual turnover, certifications and registrations — and make sure you qualify before investing effort.
  • Prepare any earnest-money deposit (EMD) or bid security and the required formats early; missing or wrongly-formatted documents are a common cause of rejection.
  • Note how bids must be submitted (online or physical), in what format, and whether a digital signature or portal registration is required.
  • Watch for corrigenda and clarifications right up to the deadline — requirements and dates can change.

More Construction & Infrastructure tenders

All Construction & Infrastructure tenders →

FreeTender mirrors this notice for reference. Verify the details and bid on the official portal.

Verify & apply on the official portal →